Effective Date: 01-June-2025

Welcome to Instacon. By accessing or using our website and services, you agree to comply with and be bound by the following Terms and Conditions. These terms apply to all visitors, customers, and users within Pakistan and beyond.

1. Introduction

Instacon is a construction and design company based in Lahore, Pakistan. Our services include architectural design, interior design, construction, finishing, and project management for residential, commercial, and hospitality projects. By using our website or engaging our services, you agree to these terms in full.

2. Scope of Services

We offer a variety of services including but not limited to:

• Residential and commercial construction

• Interior and architectural design

• Finishing and fit-out services

• MEP (Mechanical, Electrical & Plumbing) solutions

• Supervision and project management

Details and timelines of services are outlined in formal proposals or contracts issued to clients.

3. Project Terms

All projects are subject to a formal agreement outlining scope, cost, payment schedule, and timeline.
Changes to the scope after contract signing may result in additional charges and time extensions.
Client collaboration and timely feedback are essential to keep the project on schedule.

4. Payments and Invoicing

Payment terms will be clearly mentioned in the signed contract or invoice.
A percentage-based payment schedule may apply based on project milestones.
Late payments may be subject to penalties or work suspension.

5. Intellectual Property

All designs, concepts, and materials developed by Instacon remain our intellectual property unless otherwise agreed.
Clients may not reproduce, resell, or distribute our content or designs without written permission.

6. Website Usage

You may browse the site for information or to make service inquiries.
You agree not to misuse or damage the website through hacking, phishing, or any unlawful activity.
All content, logos, and images are protected and may not be copied without permission.

7. Liability Disclaimer

Instacon is not liable for indirect, incidental, or consequential damages resulting from delays, material shortages, labor issues, or client-caused disruptions.
Our obligation is limited to the services explicitly agreed upon in the contract.

8. Privacy

We respect your privacy and are committed to protecting your personal data. Please refer to our Privacy Policy for more information on how we collect and use your data.

9. Changes to Terms

We reserve the right to update or modify these Terms and Conditions at any time without prior notice. Any changes will be posted on this page with an updated revision date.

10. Governing Law

These terms shall be governed and interpreted in accordance with the laws of the Islamic Republic of Pakistan. Any disputes will be resolved in the courts of Lahore, Pakistan.

11. Contact Us

For questions or concerns regarding these Terms, please contact us at:

Instacon
10B/295 Link 9, Tufail Road, Lahore, Pakistan, 54000
Email: customercare@instacon.co
Phone: +92 321 5097527